英文合同

2022-03-31 合同范本

  随着法律观念的日渐普及,合同的法律效力与日俱增,签订合同也是避免争端的最好方式之一。相信大家又在为写合同犯愁了吧,下面是小编精心整理的英文合同5篇,仅供参考,欢迎大家阅读。

英文合同 篇1

  技 术 合 作 协 议

  Technical Cooperation Agreement

  甲方:XX油脂化学有限公司

  Party A: XX Grease Chemical Co. , Ltd.

  地址: XX高新技术工业园

  Address:XXHigh-tech Industrial Park

  法定代表人:XXX

  Legal Representative: XXX

  乙方:

  Party B:

  地址:

  Address:

  本协议合作双方就组建技术研发团队事项,经过平等协商,在真实、充分地表达各自意愿互惠互利的基础上,根据《中华人民共和国合同法》的规定,达成如下协议,并由合作各方共同恪守。

  This Agreement, concerning the setting up of a technical research and development team, is made according to the Contract Law of PRC regulations and entered into through equal negotiation by both Parties as the free and full expression of their own wishes to mutual benefits, and to this end both Parties shall abide by this Agreement as following.

  第一条、 甲方同意雇用乙方为新产品研发技术顾问。乙方同意为甲方提供技术

  顾问服务。

  Article 1: Party A hereby agrees to employ party B as the technical consultant for the new product research and development. Party B hereby agrees to offer technical consultation service to Part A.

  第二条、 甲方同意每月支付乙方的研究费用,包括:薪资、办公费、检测费、

  差旅费以及其他相关费用。

  Article 2: Party A hereby agrees to pay Party B for the research each month, including salaries, administrative expenses, detection cost, traveling expenses and other cost associated.

  第三条、 乙方有责任为甲方提供相关国内外技术及市场信息,并及时答复甲方

  技术上所遇到的问题。

  Article 3:Party B is responsible to provide relevant technical and market information home and abroad and is ready to answer any technical problem frequently asked by Party A.

  第四条、 乙方有义务向甲方提供有关个人简历和相关证明材料,甲方要尊重乙

  方个人隐私,有义务妥善保管相关材料。

  Article 4: Party B shall has the obligation to provide Party A with any relevant personal resume and reference documents as necessary. Party A shall respect the personal privacy of Party B and has the obligation to properly keep those materials.

  第五条、 乙方同意所研发的产品所有知识产权归甲方所有,乙方不得将相关技

  术信息泄露给任何第三方,否则需要承担一切法律后果。

  Article 5: Party B hereby agrees that the intellectual property of any product as researched and developed herein shall be owned by Party A. Party B shall not be allowed to disclose any technical information concerned to the third party, or it shall take all the legal consequences.

  第六条、 甲乙双方同意通过紧密合作达到共同目标;每年增加一到三个项目;

  每年申请一到三个发明专利;每年完成一到两个能够通过专家认证的

  新产品;每年至少向市场推广两个产品。

  Article 6: Both Parties agree to achieve their common goals by their close cooperation. It is planned to add one to three projects each year and to apply for one to three patents for inventions each year, to make one to two new products certified by experts each year, and to promote at least two products to the market each year.

  第七条、 此协议甲乙双方各执一份,没有在协议中提到的事项双方需协商解决。 Article 7: This Agreement is held by both Parties, one for each respectively. Any issue not mentioned in this Agreement shall be settled by both Parties through negotiation.

  此协议从签字当日起生效。

  This Agreement shall take effect from the date of signature.

  甲方:乙方:

  Party AParty B:

  签字:签字:

  Signature: Signature:

  日期:日期:

  DateDate:

英文合同 篇2

  主合同编号(Contract NO):

  买 方(Buyer):

  地 址(Add):

  电话(Tel): 传真(Fax):

  生产厂(Producer):

  地 址(Add):

  电话(Tel): 传真(Fax):020-32915578

  为体现诚实信用的合同履行精神,防止延期交货的情况出现,双方协商一致,特制定如下条款:

  In order to reflect the spirit of good faith and for avoidance of any delay in delivery, both parties hereby agree as follows:

  一、本协议是执行主合同的关于延期交货的特别约定,主合同编号为:。

  This agreement shall constitute a special covenant for implementing the provisions of delayed delivery as set forth in the Master Contract(Contract No._______).

  二、主合同约定的交货日期为: 年 月 日,运输方式为海运集装箱。

  Delivery date provided in the Master Contract shall be _________, and transportation mode is marine container.

  三、若生产厂无法按照上述交货期限的约定交货的,则买方有权要求改为空运方式运输,相应的空运费用约 美元(USD)从买方应当支付给生产厂的货款中扣除。(实际扣除金额以空运费单据为准)

  Where the Producer fails to deliver goods pursuant to the above delivery period, the Buyer has right to amend the original transportation mode to air transportation and corresponding air freight charge is around _______(USD) deductible from payments for goods made by the Buyer to the Producer. (actual deductible amount shall be subject to air freight receipts)

  买 方(Buyer):

  买方代表人:(签章)Representative: (Sgn & Samp)

  生产厂(Producer):

  生产厂代表人:(签章)Representative: (Sgn & Samp)

  签约时间: 年 月 日

  Date of Signing:(D-M-Y)

  注:本合同内容如有中英文翻译误差,以中文为准。

  Note: If this contract content has any error of translation, subject to Chinese.

英文合同 篇3

  Mrs. Ghazala Waheed wo Abdul Waheed, Adult, Ro House No.***-*, DHA, Lahore Cantt, (hereinafter to as the LESSOR of the ONE PART).

  And

  Mr.* ***,Ro China, refereed to as the LESSEE of the OTHER PART.(Expression “LESSOR”

  and “LESSEE” wherever the context so permit shall always mean and include their reective heirs, successors legal representative and assignees).

  WHEREAS the LESSOR is the lawful owner and in lawful possession of House No,***-*,DHA,

  Lahore Cantt, consisting of 4 Bedrooms with bath, DD,TV; Lounge, Kitchen, Store, Servant, Quarter together with fixtures and fitting (hereinafter collectively called the DEMISED PREMISES).

  AND WHEREAS the LESSOR has agreed the lease and the LESSEE has agreed to take on lease the DEMISED PREMISES on the terms and condition as given below:-

  1.This agreement in only valid if LESSEE is renewed and extended for the lease period.

  2. The LESSOR lets LESSEE takes the DEMISSED PREMISES for a period of 2 months

  Commencing from 5th January xx年,自 年 月____日起至_______年____月____日止。

  the tenancy shall be for a term of years,commencing on ______________and expiring on __________________.

  4.2 租赁期满,如乙方不再根据此条款续约,甲方有权收回全部出租房屋,乙方应如

  期交换出租房屋予甲方。乙方如要求续租,须在本合同期满三个月前向甲方提出书面申请,再由双方另行续租事宜。

  on expiry of the tenancy, if party b has not exercised its option to renew this agreement in accordance with this clause,party a has the right to repossess the entire leased property,and party b shall deliver the leased property to the party a provided always that party b shall have the option to renew this agreement upon giving prior written novice to party a of its intention to do so that least three(3) months before the expiration of this agreement.

  五、租金:

  rent

  5. 双方谈定的租金为每月____________________人民币,租金包括除水、电、液化气、电话费以外的一切管理费。

  the rent for the leased property as agreed to by both parties is rmb___________yuan per month, which rent includes all management fee.

  5.2 支付甲方壹个月的租金,应在每个月的第十天以前支付给甲方。

  party b pay the rental fee before the tenth day of every calendar one month.

  5.3 所有保证金、租金等费用均以人民币通过银行汇入甲方所提供的以下银行账户及户名:

  账号:____________________户名:______________开户行:____________________

  all payments of security deposit,rent fee,etc heteunder shall be made be made by bank transfer rmb to party a's following account.

  account no:________________________,user name:_____________bank:___ ________ __

  六、保证金:

  security deposit:

  6. 为确保出租房屋及其设施之安全并完好及租赁期内相关费用之如期结算,乙方同意于签订合同 0天内支付给甲方贰个月租金的租赁押金计__________________人民币作为乙方确保合同履行之保证金。乙方搬入后十天内付壹个与租金计______________人民币。

  to ensure the protection and good condition of the leased property and the related facilities as well as the prompt payment and settlement of all related charges during the term of tenancy,party b agrees to pay to party a with 0 days when the execution of this agreement a security for party b’s obligations hereunder. when party b move in,party b pay one month’s rental in the amount of___________with 0days.

  6.2 除合同另有约定之外,甲方应于租赁期满或此合同提前终止之期且乙方透空、点清并付清所有应付费用后,当天将保证金全额无息退还乙方,如保证金以人民币支付,届时也应以人民币形式退还。

  unless otherwise provided in this agreement, party a shall return to party b the entire security deposit without interest thereon upon expiration or soonder detemination of this agreement provide that party b has vzcated the leased property and settled all related charges. if this security deposit was paid in rmb,it shall be returned to party b in the form of rmb.

  七、其他费用:

  other charges:

  乙方应承担租赁期内实际使用而产生的水、电、液化气费、电话费并按单自行如期交纳所属管理公司或有关机构。

  during the term of tenancy,party b is reonsible for paying the charges in relation to water, electricity, gas,telephone charges on the basis of the amount of such utilities party b uses. such charges shall be paid when due according to the invoice therefore received by party b from the management company or relevant authority every month.

  八、甲方的责任:

  party a’s obligations:

  8. 甲方须按时将出租房屋及其家私家具用品与其设施以良好状态交付乙方使用。

  party a shall deliver on schedule to party bvacant possession of the leased property including the furniture,furnishing and appliances and the related facilities for party b’s use(furniture,furnishing and appliances to be detailed in appendisl.)

  8.2 租赁期内甲方不得收回出租房屋(除非本合同另有规定),甲方保证乙方可不受干扰的享用该物业。

  party a shall not repossess the leased property during the term of party a disturb of interfere with party b’s quiet enjoyment of the leased property.

  8.3 在乙方遵守本合同的条款及支付租金的前提下,乙方有权于租赁期内拒绝甲方或其他人骚扰而安静享用出租房屋。

  proviede that party b pays the rent and performs and observes party b’s terms and conditions in accordavce with this agreement, party b shall be entitled to hold and enjoy the leased property throughout the term of this tenancy without any interruption by party a or any other person.

  8.4 租赁期内出租房屋的结构,进出物业的排水、上下管道、电路等处于良好使用状态。

  party a agrees to repair and maintain the structure,drains, pipes and cables, etc.leading in to or from the leased property at all times in good and tenable repair during the term of this tenancy.

  九、乙方的责任:

  party b’s obligations:

  9. 乙方应按合同的规定,按时支付租金,保证金及其他各项应付费用。

  party b shall promptly pay all rent ,security deposit and other charges payable by it in accordance with the terms of this agreement.

  9.2 乙方应爱护使用出租房屋,如因乙方的过失或过错致使房屋设施及屋内用具和饰品受到损坏(正常损耗除外),乙方应负赔偿责任。

  paryt b shall treat the leased property with care. if as a result of party b’s negligence or misconduct, the leased property and the related facilities and accessorties suffer any damage(fair wear and tear excepted ),party b shall be reonsible for compensating party a for such damages.

  9.3 乙方应按本合同的约定合法使用出租房屋,不得擅自改变使用性质,不应存放中华人民共和国法律下所禁止的危险物品,如因此发生损害,乙方应承担全部责任。

  party b shall use the leased property legally as agreed in this agreement and may not change such use on its own…party b shall not store any dangerous items which are prohibited by the laws in the people’s republic of china in the leased property and shall be fully reonsible for any admages of losses as result thereof.

  9.4 未经甲方事先书面同意,乙方不得将出租房屋转租或租给其他的第三者。

  without party a’s prior written consent ,party b may not assign the tenancy or sublet the leased property to a third party.

  十、违约处理:

  breach of agreement :

  10. 1 甲、乙任何一方如未按本合同的条款履行,构成违约,应承担相应的违约责任。双方同意违约方应赔偿守约方之直接损失人民币____________元。

  if either party a or party b fails to perform its obligations hereunder ,it shall constitute a breach of this agreement and the defaulting party shall be liable for the liabilities resulting from such breach. the parties agree that the party in breach shall pay the other party compensation ____________________for the direct loss and damage suffered by the other party as result of such breach .

  10.2 乙方有下列行为之一的,甲方有权终止本合同,收回出租房屋,并且保证金不予返还;

  party a shall have the right to terminage this agreement ,repossess the leased property and forfeit the security deposit if party b commits one of the following:

  a.未得甲方书面书面同意,将出租房屋擅自转租;

  sublets the leased property without party a’s written consent;

  b.未得甲方同意将出租房擅自拆改结构或改变用途的:

  alters the structure of the leased property or uses the leased property other than for the purpose started herein without party a’s consent;

  c.无故拖欠租金超过三天(除双方就本合同存在争议除外)。

  fails to pay rent without any reason for more than thirty (30)days after the due date except where there is a diute in reect of this agreement.

  十一、适用法律:

  applicable law:

  本合同的成立,其有效性、结实、签署和解决与其他有关的一切纠纷均应受中国法律的管辖并依据中国法律解释。

  the formation of this agreement ,its validity,interpretation,executiong and settlement of any diutes arising hereunder shall be governed by and construed in accordance with the laws of the people’s republic of china.

  十二、争议的解决:

  diute resolution:

  凡因执行本合同所产生的或与本合同有关的一切争议,双方应通过友好协商解决;协商不成,应提交中国国际经济贸易仲裁委员会,按其仲裁规则和中华人民共和国仲裁法进行仲裁。仲裁解决是终局的,对双方都有约束力。

  in the case of diutes arising over this agreement of any matters related hereto ,the parties shall negotiate in good faith to resolve such diutes.if such negotiation fails, the parties shall submit the diute to arbitration by the china international economic and trade arbitration commission in accordance with its arbitration rules and the arbitration law of the people’s republic of china.the decision of the arbitration body is final and shall be binding on the parties hereto.

  十三、其他

  others:

  13. 1 本合同如有未尽事宜,由甲、乙双方洽谈解决。

  if this agreement it unclear with reect to certain matters, the two parties shall discuss to resolve such ambiguities.

  13.2 本合同由中、英文写成,两种文本具有同等效力。

  this agreement is written both in the chinese and english languages.both versions shall be equally authentic.

  13.3 本合同经双方签字后立即生效,未经双方同意,不得任意终止或修改,本合同另有约定除外,本合同一式二份,甲、乙双方各执一份。

  this agreement shall become effective upon the signing thereof by the parties hereto an registration with the relevant authorities.save and except as provided in this agreement ,this agreement may not bye terminated or amended without the consent of both parties.there are two(2) originals of this agreement ,one for party a,one for party b.

  本合同于__________年 月_____日签订。

  this agreement was signed in __________________on ________________

  甲方: 乙方:

  partya: partyb:

  盖章: 盖章:

  seal: seal:

  地址: 地址:

  address: address:

  电话: 电话:

  telephone number: telephone number:

  传真: 传真:

英文合同 篇4

  编号:

  Contract No:

  日期:

  Date:

  签约地点:

  Signed at:

  卖方:

  Sellers:

  地址:

  Address:

  邮政编码:

  Postal Code:

  电话:

  Tel:

  传真:

  Fax:

  买方:

  Buyers:

  地址:

  Address:

  邮政编码:

  Postal Code:

  电话:

  Tel: 传真:

  Fax:

  兹确认售予买方下列货品,其成交条款如下:

  The Seller hereby confirms selling the following goods on terms and conditions

  (1)公差:数量及总值均有_____%的增减,由卖方决定

  Tolerance: With _____% more or less both in amount and quantity allowed at the

  sellers option.

  (2) 原产地

  Country of Origin:

  (3) 付款方式:30%预付,70%发货前一周付清.

  Payment terms: 30% deposit, 70% payment within one week before delivery.

  (4) 交货时间:收到预付款后15天内完成装运。

  Time of shipment: Within15 days after deposit received.

  (5) 贸易方式:FOB Shanghai

  Terms of Shipment: FOB Shanghai

  (6) 包装:胶合板木盘外封铁皮

  Packing: Plywood drum with steel sheet cover.

  (7) 保险:由卖方按发票全额110%投保至_____为止的_____险。

  Insurance: To be effected by seller for 110% of full invoice value covering _____ up to _____ only.

  (8) 装运口岸:中国上海港

  Port of Loading: Shanghai Port, China

  (9) 转运:允许

  Transshipment: Allowed

  (10 分批装运:允许分批装运

  Partial Shipment: Allowed

  (11) 目的口岸:

  Port of Destination:

  (12) 唛头:Shipping Marks:

  (13) 单据:Documents:

  (14) 品质与数量、重量的异义与索赔:Quality/Quantity Discrepancy and Claim:

  (15) 逾期发运:如果由于买方原因造成逾期发运,买方承担责任。造成自签订合同之日起超过45天不能发运的,卖方将每日按货物金额的3%收取保管费;如果由于买方原因造成逾期发运超过6个月,卖方有权自行处置定金和货物。如果是卖方原因造成的逾期发运,卖方需提前告知买方并得到买方的确认并承担其他相关费用。

  LAST SHIPMENT: if the late delivery is caused by the buyer, the buyer shall bear the

  responsibility. If the delay has being made more than 45 days from the signing of the Sales Contract hereof, the buyer shall pay 3% of total amount each day, and if the delay is more than 6 months, the Seller has the right to dispose the down payment and the goods. If the late delivery is caused by the Seller, the Seller shall inform the Buyer in advance and get confirmation from the Buyer, and the related expense shall be born by the Seller.

  (16) 质量/数量异议:对于质量方面的.异议,买方必须在货物抵达目的港后30天之类提出:对于数量方面的异议,买方必须在货物抵达目的港后15天之内提出。对由于保险公司、运输公司、其他运输机构或邮局的原因所造成的货物差异,卖方不负任何责任。 QUALITY/QUANTITY DISCREPANCY: In case of quality discrepancy, claim shall be filed by the Buyer within 30 days after the arrival of the goods at port of destination; while for quantity discrepancy, claim shall be filed by the buyer within 15 days after the arrival of the goods at port of destination. It is understood that the Seller shall not be liable, for any discrepancy of goods shipped due to causes for which the Insurance Company, Shipping Company, other transportation organization or Post Office are liable.

  (17) 不可抗力:卖方对由于下列原因而导致不能或暂时不能履行全部或部分合同义务的,不负责任:水灾、火灾、地震、干旱、战争或其他任何在签约时卖方不能预料、无法控制且不能避免和克服的事件。但卖方因尽快地将所发生的事件通知对方,并应在事件发生后15天内将有关机构出具的不可抗力事件的证明寄交对方。如果不可抗力事件之影响超过120天,双方应协商合同继续履行或终止履行的事宜。

  FORCE MAJEURE: Seller shall not be responsible for failure or delay in performance of entire or portion of these Sale Contract obligations in consequence of Force Majeure incidents: flood, fire, earthquake, drought, war, or any other matters couldn’t be foreseen or controlled or couldn’t be avoided. But Seller shall inform the incidents to Buyer immediately, and shall delivery the certificate of Force Majeure incidents issued by related organization within 15 days after the incidents happened. If the incidents influence more than 120 days, both parties shall negotiate to decide whether to execute or terminate the Sales Contract.

  (18) 仲裁:因履行本合同所发生的一切争议,双方应友好协商解决,如协商仍不能解决争议,则应将争议提交中国国际经济贸易仲裁委员会(北京),依据其仲裁规则仲裁。仲裁裁决是终局的,对双方都有约束力。仲裁费应由败诉一方承担,但仲裁委员会另有裁定的除外。在仲裁期间,除仲裁部分之外的其他合同条款应继续执行。

  ARBITRATION: All disputes across from the execution of, or in connection with this Sales Contract shall be settled friendly through negotiation, in case no settlement can be reached, the case shall then be submitted to China International Economic and

  Trade Arbitration Commission, Beijing for arbitration in accordance with its provisional rules of procedure. The result of arbitration shall be born by the losing party except for the condition the Commission has other judgment. During the arbitration period, clauses beside of the arbitrated parts shall be executed.

  (19) 本合同为中英文对应,一式两份,买卖双方各执一份;合同自卖方签字盖章、买方签字后生效(传真件以及扫描具有正版相等法律效应)。

  The Sales Contract is concluded in Chinese and English with same effectiveness, and will come into effect on stamp of Seller and signing by Buyer. The Sales Contract is in dual original and each party shall have one original copy of this Sales Contract. (Any scanned and faxed copy shall have the same legal effect as the original one.)

  (20) 备注:

Remark:

  买方确认签署: 卖方确认签署:

  For and on behalf of Buyer: For and on behalf of Seller:

英文合同 篇5

  一.hereby

  英文释义:by means of , by reason of this

  中文译词:特此,因此,兹

  用法:常用于法律文件、合同、协议书等正式文件的开头语;在条款中需要强调时也可用。

  语法:一般置于主语后,紧邻主语.

  例1:

  The Employer hereby covenants to pay the Contractor in consideration of the execution and completion of the Works and the remedying of defects therein the Contract Price or such other sum as may become payable under the provisions of the Contract at the time and in the manner prescribed by the Contract.

  参考译文:

  业主特此立约保证在合同规定的期限内,按合同规定的方式向承包人支付合同价,或合同规定的其它应支付的款项,以作为本工程施工、竣工及修补工程中缺陷的报酬。

  注释:

  (1)hereby: by reason of this 特此

  (2)covenant: v. make a formal agreement 立约,签订合同、条约; n. legal agreement具有法律约束的正式合同

  (3)completion of the Works: 工程的竣工

  (4)therein: in the Works在本工程中

  (5)the Contract Price: 合同总价,指工程的总造价

  (6)such...as: 关系代词,相当于that, which

  (7)under: in accordance with 根据,按照

  (8)the provisions of the Contract: terms and conditions of the Contract合同条款

  例2:

  We hereby certify to the best of our knowledge that the foregoing statement is true and correct and all available information and data have been supplied herein, and that we agree to provide documentary proof upon your request.

  注释:

  (1)hereby:特此

  (2)to the best of our knowledge:as far as we know据我们所知

  (3)foregoing statement:above-mentioned statement上述声明

  (4)herein:in this, in the statement在声明中

  (5)documentary proof:证明文件

  参考译文:

  特此证明,据我们所知,上述声明内容真实,正确无误,并提供了全部现有的资料和数据,我们同意,应贵方要求出具证明文件。

  例3:

  This Contract is hereby made and concluded by and between Co. (hereinafter referred to as Party A) and Co. (hereinafter referred to as Party B) on (Date), in (Place), China, on the principle of equality and mutual benefit and through amicable consultation.

  注释:

  (1)hereby:特此

  (2)hereinafter referred to as Party A:以下称甲方

  (3)on the principle of equality and mutual benefit:在平等互利基础上

  (4)through amicable consultation:通过友好协商

  参考译文:

  本合同双方, 公司(以下称甲方)与 公司(以下称乙方),在平等互利基础上,通过友好协商,于 年 月 日在中国 (地点),特签订本合同。

  例4:

  This agreement is hereby made and entered into on (Date), by and between Co. China (hereinafter referred to as Party A) and Co. (hereinafter referred to as Party B).

  注释:

  (1)this agreement is hereby made and entered into:特此订立本协议 在法律文件中表示“订立本协议”可用以下4个动词:sign (make, conclude or enter into) this agreement, 按照同义词连用的写作特点,可用上述4个动词中的两个来表示)。

  (2)hereinafter referred to as Party B:以下简称乙方

  参考译文:

  本协议特由中国 公司(以下简称甲方)与 公司(以下简称乙方)于 年 月 日订立。

  二 hereof

  英文释义: of this

  中文译词:关于此点;在本文件中

  用法:在表示上文已提及的“本合同的、本文件的??”时,使用该词。例如表示本合同条件、条款时,可以说“the terms, conditions and provisions hereof”,这里hereof表示“of this Contract”;又如表示本工程的任何部分,可用“any parts hereof”,这里hereof表示“of this Works”。 语法:一般置于要修饰的名词的后面,与之紧邻。

  hereof和thereof的区别:hereof强调“of this”。例如,上面的“the terms, conditions and provisions thereof”中的thereof表示of the Contract;“any parts thereof”中的thereof表示of the Works。

  例1

  Whether the custom of the Port is contrary to this Clause or not, the owner of the goods shall, without interruption, by day and night, including Sundays and holidays (if required by the carrier), supply and take

  delivery of the goods. Provided that the owner of the goods shall be liable for all losses or damages including demurrage incurred in default on the provisions hereof.

  注释:

  (1) Whether the custom of the Port is contrary to this Clause or not:不论港口习惯是否与本款规定相反,whether? or not:不论??是否

  (2) the owner of the goods:货方

  (3) without interruption:无间断地

  (4) carrier:承运人

  (5) in default on the provisions hereof:违反本款规定 hereof:of this Clause

  参考译文:

  不论港口习惯是否与本款规定相反,货方都应昼夜地,包括星期日和假日(如承运人需要),无间断地提供和提取货物。货方对违反本款规定所引起的所有损失或损坏,包括滞期应负担赔偿责任。

  例2

  Foreign trade dealers as mentioned in this Law shall, in accordance with the provisions hereof, cover such legal entities and other organization as are engaged in foreign trade dealings.

  注释:

  (1) foreign trade dealers:对外贸易经营者

  (2) as mentioned in this Law:本法所称

  (3) the provisions hereof:the provisions of this Law 本法规定

  (4) legal entity:法人

  (5) be engaged in foreign trade dealings:从事对外贸易经营活动 参考译文:

  本法所称对外贸易经营者,是指依照本法规定从事对外贸易经营活动的法人和其他组织。

  例3

  The establishment of a limited liability company or a company limited by shares shall comply with the conditions and provisions of this Law. A company complying with the conditions and provisions hereof may be registered as a limited liability company or a company limited by shares. Provided that if a company fails to comply with the conditions and provisions hereof, the company in question shall not be registered as a limited liability company or a company limited by shares.

  注释:

  (1)a limited liability company:有限责任公司

  (2)a company limited by shares:股份有限公司

  (3)provisions hereof:本法规定 hereof: of this Law

  (4)may be registered as:登记为

  参考译文:

  设立有限责任公司、股份有限公司,必须符合本法规定的条件。符合本法规定的条件的,登记为有限责任公司或者股份有限公司;不符合本法规定的条件的,不

  得登记为有限责任公司或股份有限公司。

  例4

  If, as a result of withdrawal or any other reasons, an arbitrator fails to perform his duties as an arbitrator, another arbitrator shall, in accordance with the provisions hereof, be selected or appointed. 注释:

  (1) as a result of withdrawal or any other reasons:回避或者其它原因

  (2) arbitrator:仲裁员

  (3) the provisions hereof:the provisions of this Law 本法规定

  (4) be selected or appointed:选定或指定

  参考译文:

  仲裁员因回避或者其它(转 载于:wWw.cnboThwiN.cOM 博 威范文 网:协议书英文怎么写)原因不能履行职责的,应当依照本法规定重新选定或指定仲裁员。

  例5

  In the event of conflict between the provisions on arbitration formulated and prepared prior to the effective date of this Law and the provisions of this Law, the provisions hereof shall prevail.

  注释:

  (1) conflict:相抵触

  (2) prior to the effective date of this Law:本法施行前

  (3) the provisions hereof shall prevail:以本法为准 hereof:of this Law 参考译文:

  本法施行前制定的有关仲裁的规定与本法的规定相抵触的,以本法为准。 例6

  Where, in accordance with laws, the circumstance(s) specified in Article 15 and Article 16 of this Law is /are confirmed, the organization with compensatory obligations shall pay compensation in any of the circumstance in question.

  Where the claimant for compensation demands the confirmation of one of the circumstances specified in Article 15 and Article 16 hereof, and the demanded organization refuses to make the confirmation, the claimant shall have the right to lodge a complaint. Where the claimant claims compensation, the claim, shall, first, be lodged to the organization for compensatory obligations.

  The provisions of Article 10, Article 11 and Article 12 hereof shall apply to/ in the procedures of compensation.

  注释:

  (1) the organization with compensatory obligations:赔偿义务机关

  (2) shall pay compensation:应当给予赔偿

  (3) the claimant for compensation:赔偿请求人

  (4) Article 15 and Article 16 hereof:本法第十五条、第十六条 hereof:of this Law

  (5) shall have the right to lodge a complaint:有权申诉

  (6) claims compensation:要求赔偿

  (7) apply to/ in:适用 More Examples: The comment applies equally here. /That argument does not apply in this case. /That applies to at least nine-tenths of the people we see about. /These remarks apply to every town in this kingdom. /The rules of safe driving apply to everyone. 参考译文:

  赔偿义务机关对依法确认有本法第十五条、第十六条规定的情形之一的,应当给予赔偿。

  赔偿请求人要求确认有本法第十五条、第十六条规定情形之一的,被要求的机关不予确认的,赔偿请求人有权申诉。赔偿请求人要求赔偿,应当先向赔偿义务机关提出。赔偿程序适用本法第十条、第十一条、第十二条的规定。

  例7

  If an arbitrator involved in one of circumstances specified in Item 4, Article 34 of this Law, and if it is serious, or those specified in Item 6, Article 58 hereof, the arbitrator in question shall, in accordance with the law, bear the legal liability and responsibility. The arbitration commission shall remove the name of the arbitrator in question from the list of arbitrators.

  注释:

  (1) arbitrator:仲裁员

  (2) Article 58 hereof:本法第五十八条 hereof:of this Law

  (3) bear the legal liability and responsibility:承担法律责任

  (4) the arbitration commission:仲裁委员会

  (5) remove the name of the arbitrator in question from the list of arbitrators:将其除名

  参考译文:

  仲裁员有本法第三十四条第四项规定的情形,情节严重的,或者有本法第五十八条第六项规定的情形的,应当依法承担法律责任,仲裁委员会应当将其除名。 例8

  If, pursuant to this Law, the relevant responsible authorities with the duty of approvals fail to grant approval to such an application as meets the requirements and provisions hereof, or the company registration authorities fail to register a company whose application meets the requirements hereof, the party in question may, in accordance with laws, apply for reconsideration or bring an administrative suit.

  注释:

  (1) the relevant responsible authorities with the duty of approvals:履行审批职责的有关主管部门

  (2) meets the requirements and provisions hereof:符合本法条件

  (3) the company registration authorities:负责公司登记的主管部门

  (4) the requirements hereof:本法条件 hereof: of this Law

  (5) apply for reconsideration:申请复议

  (6) bring an administrative suit:提起行政诉讼

【英文合同模板集锦五篇】相关文章:

英文合同模板集锦5篇03-26

英文合同模板集合六篇03-30

英文合同模板汇总8篇03-25

英文合同模板汇编10篇03-22

英文合同模板汇总7篇03-14

英文实习证明模板01-21

实习证明模板 英文11-12

最新英文讣告模板09-25

实用的英文感谢信模板集锦8篇02-26

实用的英文感谢信模板集锦八篇02-24

药品采购合同简易版 粮油采购合同简单版